CalCruz Express Material and Labor Bond GP16-046PFOR: Grading / Drainage $
Erosion Control $WQMP $Total $
Surety
Addresscity/state-7rn_
Phone
MATERIAL AND LABOR BOND
CITY OF IVENIFEE, STATE OF CALIFORNIA
(Government Code Section 66499.1)
132.500.00 Tract
17 500.00 Other Project No
Bond No.46 750
199 750.00 Premium $
Principal Ca I Cruz Express
Address 34193 Camelina St.
City/State Lake Elsinore, CA
GP16-046P
zip 92532
Phone (541) 501-8141
WHEREAS, the City of Menifee, State of California, and Cal C ruz Express , (hereinafter
designated as "principal") have entered into, or are about to enter into, the attached
agreement(s) whereby principal agrees to install and complete the above designated Grading,
Erosion Control & WQMP relating to GP16-046P , which agreement(s) is/are hereby referred
to and made a part hereof; and,
WHEREAS, under the terms of said agreement, principal is required, before entering upon
the performance of the work, to file a good and sufficient payment bond with the City of
Menifee to secure the claims to which reference is made in Title 15 (commencing with Section
3082) of Part 4 of Division 3 of the Civil Code of the State of California;
NOW, THEREFORE, said principal and the undersrgned, as corporate surety, are held firmly
unto the City of Menifee and all contractors, subcontractors, laborers, material persons and
other persons employed in the performance of said Civil Code in the sum of One Hundred
Ninetv Nine Thousand Seven Hund red Fiftv and no/100 ,Dollars, $ 199.750.00 for
materials furnished or labor thereon of any kind, or for amounts due under the Unemployment
lnsurance Act with respect to such work or labor, that said surety will pay the same in an
amount not exceeding the amount hereinabove set forth, and also in case suit is brought
upon this bond, will pay, in addition to the face amount thereof, costs and reasonable
expenses and fees, including reasonable attorney's fees, incurred by the City in successfully
enforcing such obligation, to be awarded and fixed by the court, and to be taxed as costs and
to be included in the judgment therein rendered.
It is hereby expressly stipulated and agreed upon that this bond shall inure to the benefit of
any and all persons, companies and corporations entitles to full claims under Title 15
(commencing with Section 3082) of Parl 4 of Division 3 of the Civil Code, so as to give a right
of action to them or their assigns in any suit brought upon this bond.
Should the condition of this bond be fully performed, then this obligation shall become null
and void; otherwise, it shall be and remain in full force and effect.
9i8115
M EN IFEE
MATERIAL AND LABOR BOND
The surety hereby stipulates and agrees that no change, extension of time, alteration or
addition to the terms of this agreement or to the specifications accompanying the same shall
in anywise affect its obligation on this bond, and it does hereby waive notice of any such
change, extension of time, alteration or addition. Surety further stipulates and agrees that the
provisions of Section 2845 of the Civil Code are not a condition precedent to surety's
obligations hereunder and are hereby waived by surety.
lN WITNESS WHEREOF, this instrument has been duly executed by the principal and surety
above named, on
AUTHORIZED SIGNATURE(S):
By:
Name:
Title:
(IF CORPORATION, AFFIX SEAL)
NAIVE OF SURETY:
AUTHORIZED SIGNATURE:
Its Attorney-in-Fact Title
(IF CORPORATION, AFFIX SEAL)
ATTACH NOTARIAL ACKNOWLEDGMENT OF SIGNATURES OF PRINCIPAL AND
ATTORNEY.IN.FACT.
9/8/15
NAME OF PRINCIPAL: